Trade Terms

Pools for Canterbury Ltd – Terms & Conditions of Trade

1. Definitions

1.1 “Seller” shall mean Pools for Canterbury Ltd, its successors and assigns or any person acting on behalf of and with the authority of Pools for Canterbury Ltd.

1.2 “Client” shall mean the Client (or any person acting on behalf of and with the authority of the Client) as described on any quotation, work authorisation or other form as provided by the Seller to the Client.

1.3 “Guarantor” means that person (or persons), or entity, who agrees to be liable for the debts of the Client on a principal debtor basis.

1.4 “Goods” shall mean Goods supplied by the Seller to the Client (and where the context so permits shall include any supply of Services as hereinafter defined) and includes Goods described on any invoices, quotation, work authorisation or any other forms as provided by the Seller to the Client.

1.5 “Services” shall mean all works and/or services supplied by the Seller to the Client and includes any advice or recommendations (and where the context so permits shall include any supply of Goods as defined above).

1.6 “Price” shall mean the price payable for the Goods as agreed between the Seller and the Client in accordance with clause 3 of this contract.

2. Acceptance

2.1 Any instructions received by the Seller from the Client for the supply of Goods and/or the Client’s acceptance of Goods supplied by the Seller shall constitute acceptance of the terms and conditions contained herein.

2.2 Where more than one Client has entered into this agreement, the Clients shall be jointly and severally liable for all payments of the Price.

2.3 Upon acceptance of these terms and conditions by the Client the terms and conditions are binding and can only be amended with the written consent of the Seller.

2.4 The Client shall give the Seller not less than fourteen (14) days prior written notice of any proposed change of ownership of the Client or any change in the Client’s name and/or any other change in the Client’s details (including but not limited to, changes in the Client’s address, facsimile number, or business practice). The Client shall be liable for any loss incurred by the Seller as a result of the Client’s failure to comply with this clause.

3. Price and Payment

3.1 At the Seller’s sole discretion the Price shall be either:

(a) as indicated on invoices provided by the Seller to the Client in respect of Goods supplied; or

(b) the Seller’s quoted Price (subject to clause 4) which shall be binding upon the Seller provided that the Client shall accept the Seller’s quotation in writing within thirty (30) days and the work commences within the timeframe advised in the cover email. If the work does not commence within this timeframe, the Seller reserves the right to charge the Client for any reasonable increase in the costs to carry out the work and/or supply goods.

3.2 At the Seller’s sole discretion, a deposit may be required.

3.3 Payment of the Price shall be subject to retention by the Client of an amount (hereafter called the “retention money”), being equal to a 10% of the Price. The Client shall hold the retention money for the agreed period following completion of the works during which time all works are to be completed and/or all defects are to be remedied.

3.4 The Seller may submit a detailed payment claim for work performed up to the date of the invoice. The value of work so performed shall include the reasonable value of authorised variations, whether or not the value of such variations has been finally agreed between the parties, and the value of materials delivered to the site, or held in storage on the Client’s behalf, but not yet installed.

3.5 At the Seller’s sole discretion, payment is required as set out in the accepted quote.

3.6 Time for payment for the Goods shall be of the essence and will be stated on the invoice or any other forms. If no time is stated, then payment shall be due seven (7) days following the date of the invoice.

3.6 Payment will be made by cash, or by cheque, or by bank cheque, or by direct credit, or by any other method as agreed to between the Client and the Seller.

3.7 GST and other taxes and duties that may be applicable shall be added to the Price except when they are expressly included in the Price.

3.8 The contract price agreed between the Seller and the Client for the pool and its installation has been calculated based on current market prices. The market for pool construction, shipping and delivery is considered volatile, and sudden price increases could occur. The Seller agrees to use its best efforts to obtain the lowest possible prices in securing and delivering pools, but should there be an increase in these prices after acceptance of the quote by the Client and accordingly the execution of these Terms and Conditions of Trade, the Client agrees to pay that cost increase to the Seller. Any claim by the Seller for payment of a cost increase, as provided above, shall require written notice delivered by the Seller to the Client stating the increased cost, what this increased cost relates to and be supported by invoices.

4. Variations

4.1 Any variation from the plan of scheduled works or specifications (including, but not limited to, any variation as a result of additional works required due to hidden or unidentifiable difficulties beyond the reasonable control of the Seller such as hard rock barriers below the surface or iron reinforcing rods in concrete) will be made in writing and charged for on the basis of the Seller’s quotation and will subsequently be shown as variations on any invoice.

4.2 In the event of a variation as per 4.1 then the Client shall have the option to either accept the variation or to cancel the contract. In the event of cancellation then clause 19.2 shall apply and the Seller shall deduct any monies that then become due from any monies already paid and refund any surplus to the Client.

5. Delivery of Goods

5.1 At the Seller’s sole discretion delivery of the Goods shall take place when:

(a) the Client takes possession of the Goods at the Seller’s address; or

(b) the Client takes possession of the Goods at the Client’s nominated address (in the event that the Goods are delivered by the Seller or the Seller’s nominated carrier).

5.2 At the Seller’s sole discretion, the costs of delivery are in addition to the Price, or for the Client’s account, unless specifically stated otherwise in the contract.

5.3 The Client shall make all arrangements necessary to take delivery of the Goods whenever they are tendered for delivery. In the event that the Client is unable to take delivery of the Goods as arranged then the Seller shall be entitled to charge a reasonable fee for redelivery.

5.4 Delivery of the Goods to a third party nominated by the Client is deemed to be delivery to the Client for the purposes of this agreement.

5.5 The Seller shall not be liable for any loss or damage whatever due to failure by the Seller to deliver the Goods (or any of them) promptly.

6. Risk

6.1 If the Seller retains ownership of the Goods nonetheless, all risk for the Goods passes to the Client on delivery.

6.2 If any of the Goods are damaged or destroyed following delivery but prior to ownership passing to the Client, the Seller is entitled to receive all insurance proceeds payable for the Goods. The production of these terms and conditions by the Seller is sufficient evidence of the Seller’s rights to receive the insurance proceeds without the need for any person dealing with the Seller to make further enquiries.

6.3 Following installation the care, maintenance and cleanliness of a pool shall be the responsibility of the Client.

6.4 The Seller will not accept any liability for discolouration, staining or roughness which may occur to or upon the pool surface caused by algae infestation, calcium scales, weed or vegetation deposit or mineral build up.

7. Damages

7.1 The Seller will take all due care to preserve the natural surroundings of the Client’s property however the Seller shall not be liable for any loss or damage to gardens, trees, lawns, shrubs, fences, paths, or driveways which may be caused by the ordinary operation of trucks, machinery, vehicles or equipment.

8. Underground Locations

8.1 Prior to the Seller commencing any work the Client must advise the Seller of the precise location of all underground services on the site and clearly mark the same. The underground mains & services the Client must identify include, but are not limited to, electrical services, gas services, sewer services, pumping services, sewer connections, sewer sludge mains, water mains, irrigation pipes, Telstra cables, fibre optic cables, oil pumping mains, and any other services that may be on site.

8.2 Whilst the Seller will take all care to avoid damage to any underground services the Client agrees to indemnify the Seller in respect of all and any liability claims, loss, damage, costs, and fines as a result of damage to services not precisely located and notified as per clause 8.1.

9. Compliance with Laws

9.1 The Client shall obtain (at the expense of the Client) all licences and approvals that may be required for the works.

9.2 Whilst the Seller will endeavour to advise the Client of all relevant legislation relating to pool installations the Client acknowledges that is their responsibility to ensure that they comply with any occupational health and safety laws relating to pool installations and any other relevant safety standards or legislation.

10. Insurance

10.1 The Seller shall have public liability insurance of at least two million dollars ($2,000,000).

10.2 It is the Clients responsibility to effect such insurance as they deem necessary in respect of the swimming pool or its installation.

11. Title

11.1 The Seller and Client agree that ownership of the Goods shall not pass until:

(a) the Client has paid the Seller all amounts owing for the particular Goods; and

(b) the Client has met all other obligations due by the Client to the Seller in respect of all contracts between the Seller and the Client.

11.2 Receipt by the Seller of any form of payment other than cash shall not be deemed to be payment until that form of payment has been honoured, cleared or recognised and until then the Seller’s ownership or rights in respect of the Goods shall continue.

11.3 It is further agreed that:

(a) where practicable the Goods shall be kept separate and identifiable until the Seller shall have received payment and all other obligations of the Client are met; and

(b) until such time as ownership of the Goods shall pass from the Seller to the Client the Seller may give notice in writing to the Client to return the Goods or any of them to the Seller. Upon such notice being given the rights of the Client to obtain ownership or any other interest in the Goods shall cease; and (c) the Client is only a bailee of the Goods and until such time as the Seller has received payment in full for the Goods then the Client shall hold any proceeds from the sale or disposal of the Goods on trust for the Seller; and

(d) until such time that ownership in the Goods passes to the Client, if the Goods are converted into other products, the parties agree that the Seller will be the owner of the end products; and

(e) if the Client fails to return the Goods to the Seller then the Seller or the Seller’s agent may enter upon and into land and premises owned, occupied or used by the Client, or any premises where the Goods are situated as the invitee of the Client and take possession of the Goods, and the Seller will not be liable for any reasonable loss or damage suffered as a result of any action by the Seller under this clause.

12. Client’s Disclaimer

12.1 The Client hereby disclaims any right to rescind, or cancel any contract with the Seller or to sue for damages or to claim restitution arising out of any inadvertent misrepresentation made to the Client by the Seller and the Client acknowledges that the Goods are bought relying solely upon the Client’s skill and judgment.

13. Defects

13.1 The Client shall inspect the Goods on delivery and shall within seven (7) days of delivery (time being of the essence) notify the Seller of any alleged defect, shortage in quantity, damage or failure to comply with the description or quote. The Client shall afford the Seller an opportunity to inspect the Goods within a reasonable time following delivery if the Client believes the Goods are defective in any way. For defective Goods, which the Seller has agreed in writing that the Client is entitled to reject, the Seller’s liability is limited to either (at the Seller’s discretion) replacing the Goods or repairing the Goods.

14. Returns

14.1 Returns will only be accepted provided that:

(a) the Client has complied with the provisions of clause 13.1; and

(b) the Seller will not be liable for Goods which have not been stored or used in a proper manner; and

(c) the Goods are returned in the condition in which they were delivered and with all packaging material, brochures, and instruction material in as new condition as is reasonably possible in the circumstances.

14.2 Goods made to special order, Client specification or non-stock items and ex stock pools sold at a reduced price, are under no circumstances acceptable for credit or return. Cancellation of orders for special or non-stock items will definitely not be accepted, once these orders are in production.

15. Warranty

15.1 Subject to the conditions of warranty set out in Clause 15.2 the Seller warrants that if any defect in any workmanship of the Seller becomes apparent and is reported to the Seller within twelve (12) months of the date of delivery (time being of the essence) then the Seller will either (at the Seller’s sole discretion) replace or remedy the workmanship.

15.2 The conditions applicable to the warranty given by Clause 15.1 are:

(a) The warranty shall not cover any defect or damage which may be caused or partly caused by or arise through:

(i) Failure on the part of the Client to properly maintain any Goods; or

(ii) Failure on the part of the Client to follow any instructions or guidelines provided by the Seller; or

(iii) Any use of any Goods otherwise than for any application specified on a quote or order form; or

(iv) The continued use of any Goods after any defect becomes apparent or would have become apparent to a reasonably prudent operator or user; or (v) Fair wear and tear, any accident or act of God.

(b) The warranty shall cease, and the Seller shall thereafter in no circumstances be liable under the terms of the warranty if the workmanship is repaired, altered or overhauled without the Seller’s consent.

(c) In respect of all claims the Seller shall not be liable to compensate the Client for any delay in either replacing or remedying the workmanship or in properly assessing the Client’s claim.

15.3 For Goods not manufactured by the Seller, the warranty shall be the current warranty provided by the manufacturer of the Goods. The Seller shall not be bound by nor be responsible for any term, condition, representation, or warranty other than that which is given by the manufacturer of the Goods.

15.4 Manufacturers warranty covering spas, pools, covers, filtration plant and other equipment specified, apply from the date of installation. During the warranty period any part or parts that fail due to faulty workmanship or material will be replaced free of charge.

16. Consumer Guarantees Act 1993

16.1 If the Client is acquiring Goods for the purposes of a trade or business, the Client acknowledges that the provisions of the Consumer Guarantees Act 1993 do not apply to the supply of Goods by the Seller to the Client.

17. Intellectual Property

17.1 Where the Seller has designed, drawn or written Goods for the Client, then the copyright in those designs and drawings and documents shall remain vested in the Seller, and shall only be used by the Client at the Seller’s discretion.

17.2 The Client warrants that all designs or instructions to the Seller will not cause the Seller to infringe any patent, registered design or trademark in the execution of the Client’s order and the Client agrees to indemnify the Seller against any action taken by a third party against the Seller in respect of any such infringement.

18. Default & Consequences of Default

18.1 Interest on overdue invoices shall accrue from the date when payment becomes due daily until the date of payment at a rate of 2.5% per calendar month and such interest shall compound monthly at such a rate after as well as before any judgment.

18.2 If the Client defaults in payment of any invoice when due, the Client shall indemnify the Seller from and against all costs and disbursements incurred by the Seller in pursuing the debt including legal costs on a solicitor and own client basis and the Seller’s collection agency costs.

18.3 Without prejudice to any other remedies the Seller may have, if at any time the Client is in breach of any obligation (including those relating to payment), the Seller may suspend or terminate the supply of Goods to the Client and any of its other obligations under the terms and conditions. The Seller will not be liable to the Client for any loss or damage the Client suffers because the Seller has exercised its rights under this clause.

18.4 If any account remains overdue after thirty (30) days then an amount of the greater of $20.00 or 10.00% of the amount overdue (up to a maximum of $200) shall be levied for administration fees which sum shall become immediately due and payable.

18.5 Without prejudice to the Seller’s other remedies at law the Seller shall be entitled to cancel all or any part of any order of the Client which remains unfulfilled and all amounts owing to the Seller shall, whether or not due for payment, become immediately payable in the event that:

(a) any money payable to the Seller becomes overdue, or in the Seller’s opinion the Client will be unable to meet its payments as they fall due; or (b) the Client becomes insolvent, convenes a meeting with its creditors or proposes or enters into an arrangement with creditors, or makes an assignment for the benefit of its creditors; or

(c) a receiver, manager, liquidator (provisional or otherwise) or similar person is appointed in respect of the Client or any asset of the Client.

19. Cancellation

19.1 The Seller may cancel any contract to which these terms and conditions apply or cancel delivery of Goods at any time before the Goods are delivered by giving written notice to the Client. On giving such notice the Seller shall repay to the Client any sums paid in respect of the Price. The Seller shall not be liable for any loss or damage whatever arising from such cancellation.

19.2 In the event that the Client cancels delivery of Goods any deposit paid by the client shall be forfeited to the Seller and the Client shall be liable for full costs of any Works, Goods and/or Services provided by the Seller, including any Works and/or Goods ordered and/or purchased, up to the time of cancellation as well as any loss incurred by the Seller (including, but not limited to, any loss of profits).

19.3 In the event of cancellation by the Client then the Seller shall not be under any obligation to restore the Client’s property to the condition it was in, prior to commencement of the works.

19.4 This clause shall not apply where the client cancels the contract because the Seller has repudiated or otherwise substantially breaches the contract.

20. Privacy Act 2020

20.1 The Client and the Guarantor/s (if separate to the Client) authorises the Seller to:

(a) collect, retain and use any information about the Client, for the purpose of assessing the Client’s creditworthiness or marketing products and services to the Client; and

(b) disclose information about the Client, whether collected by the Seller from the Client directly or obtained by the Seller from any other source, to any other credit provider or any credit reporting agency for the purposes of providing or obtaining a credit reference, debt collection or notifying a default by the Client.

20.2 Where the Client and/or Guarantors are an individual the authorities under clause 20.1 are authorities or consents for the purposes of the Privacy Act 1993.

20.3 The Client and/or Guarantors shall have the right to request the Seller for a copy of the information about the Client and/or Guarantors retained by the Seller and the right to request the Seller to correct any incorrect information about the Client and/or Guarantors held by the Seller.

21. Unpaid Seller’s Rights

21.1 Where the Client has left any item with Seller for repair, modification, exchange or for the Seller to perform any other Service in relation to the item and Seller has not received or been tendered the whole of the Price, or the payment has been dishonoured, the Seller shall have:

(a) a lien on the item;

(b) the right to retain the item for the Price while the Seller is in possession of the item; (c) a right to sell the item.

21.2 The lien of the Seller shall continue despite the commencement of proceedings, or judgement for the Price having been obtained.

22. Construction Contracts Act 2002

22.1 In the event that the Client is a residential occupier as defined by the Construction Contracts Act 2002 the Client hereby expressly acknowledges that: (a) the Seller has the right to suspend work within five (5) working days of written notice of its intent to do so if a payment claim is served on the Client, and: (i) the payment is not paid in full by the due date for payment and no payment schedule has been given by the Client; or

(ii) a scheduled amount stated in a payment schedule issued by the Client in relation to the payment claim is not paid in full by the due date for its payment; or

(iii) the Client has not complied with an adjudicator’s notice that the Client must pay an amount to the Seller by a particular date; and (iv) the Seller has given written notice to the Client of its intention to suspend the carrying out of construction work under the construction contract. (b) if the Seller suspends work, it:

(i) is not in breach of contract; and

(ii) is not liable for any loss or damage whatsoever suffered, or alleged to be suffered, by the Client or by any person claiming through the Client; and

(iii) is entitled to an extension of time to complete the contract; and

(iv) keeps its rights under the contract including the right to terminate the contract; and may at any time lift the suspension, even if the amount has not been paid or an adjudicator’s determination has not been complied with.

(c) if the Seller exercises the right to suspend work, under Clause 22.1(a), the exercise of that right does not:

(i) affect any rights that would otherwise have been available to the Seller under the Contractual Remedies Act 1979; or

(ii) enable the Client to exercise any rights that may otherwise have been available to the Client under that Act as a direct consequence of the Seller suspending work under this provision.

23. General

23.1 If any provision of these terms and conditions shall be invalid, void, illegal or unenforceable the validity, existence, legality, and enforceability of the remaining provisions shall not be affected, prejudiced, or impaired.

23.2 These terms and conditions and any contract to which they apply shall be governed by the laws of New Zealand and are subject to the jurisdiction of the courts of New Zealand.

23.5 The Client shall not be entitled to set off against or deduct from the Price any sums owed or claimed to be owed to the Client by the Seller.

23.6 The Seller may not license or sub-contract all or any part of its rights and obligations without the Client’s consent; such consent not to be unreasonably withheld.

23.7 The Seller reserves the right to review these terms and conditions at any time. If, following any such review, there is to be any change to these terms and conditions, then that change will take effect from the date on which the Seller notifies the Client of such change, and the Client agrees.

23.8 The provisions of the Contractual Remedies Act 1979 shall apply to this contract as if section 15(d) were omitted from the Contractual Remedies Act 1979.

23.9 Neither party shall be liable for any default due to any act of God, war, terrorism, strike, lock-out, industrial action, fire, flood, drought, storm, or other event beyond the reasonable control of either party.

23.10 The failure by the Seller to enforce any provision of these terms and conditions shall not be treated as a waiver of that provision, nor shall it affect the Seller’s right to subsequently enforce that provision.